—

## **SJVN Limited – Tender Notice**

### Project Overview

* **Work Name:** Engineering, Procurement & Construction (EPC) of **5 MW Solar PV Power Plant**.
* **Location:** **Gujarat** (Charanka Solar Park).
* **Scope:**

* Complete **EPC** including design, supply, installation, testing & commissioning of a **5 MW solar PV project**.
* **Operation & Maintenance (O\&M) for 10 years** post-commissioning.
* Evacuation up to **33 kV substation** within the park.

—

### Timeline

* **Tender Publish Date:** 06.08.2025
* **Bid Submission Deadline:** 28.08.2025 (14:00 hrs)
* **Technical Bid Opening:** 29.08.2025 (15:00 hrs)
* **Financial Bid Opening:** To be intimated later.

—

### Financials

* **Estimated Cost:** ₹26.5 crore
* **EMD:** ₹53 lakh
* **Tender Fee:** ₹5,000 (incl. GST)

—

### Eligibility Criteria

**Technical:**

* EPC of grid-connected solar projects ≥2 MW in last 7 years:

* One project ≥80% (≥4 MW), OR
* Two projects ≥50% (≥2.5 MW each), OR
* Three projects ≥40% (≥2 MW each).
* Must have executed solar evacuation at **33 kV or higher** voltage level.

**Financial:**

* Avg. annual turnover ≥₹7.95 crore in last 3 years.
* Positive net worth in last FY.

—

### Tender Authority

* **Issuer:** SJVN Limited, Renewable Energy Division, Shimla.
* **Contact:** RE Tender Cell, SJVN Ltd.

—

For more information please see below link:

This is in reference to the RfS for “Selection of Solar Project Developers for setting up of 3850 kW Grid-Connected Rooftop Solar PV Projects under RESCO mode through Tariff-based Competitive Bidding (RTSPV-Tranche-I)” issued by SECI.

Pre-bid meeting for the RfS has been scheduled as per following details:

Date & Time: 03.07.2025 at 02:30 PM (IST).

Mode of meeting: Online mode

Pre-bid meeting link: https://teams.microsoft.com/l/meetupjoin/19%3aXTet8N6xkE_6eHvy05IhHjREk102bgbYd2exX2o3pU1%40thread.tacv2/1750841267039?context=%7b%22Tid%22%3a22a24b3e19-3a1f4c61-9f1e-cace38462ab7%22%2c%22Oid%22%3a%225164b124-35cd-46f3-97d9-6f9cc331e98c%22%7d

The online meeting will be conducted through video-conferencing on the Microsoft Teams Platform.

Invitations for the meeting will be sent out on 02.07.2025.

If you have any queries, please contact us at abhisekhsri@seci.co.in or swapnil.gandhi@seci.co.in.

Prospective bidders are requested to remain updated for any notices/ amendments/ clarifications etc. to the NIT documents through the websites www.seci.co.in and https://www.bharat-electronictender.com as no separate notification will be issued.

Tender Search Code (TSC) for the NIT in ISN-ETS: SECI-2025-TN000013

—

## **Gujarat Electricity Regulatory Commission (GERC) – Daily Order**

### Case Details

* **Petition No.:** 2484 of 2025
* **Petitioner:** Gujarat Urja Vikas Nigam Limited (GUVNL)
* **Respondents:**

1. Welspun Renewable Energy Ltd. – 50 MW @ ₹2.60/unit
2. Avaada Energy Pvt. Ltd. – 100 MW @ ₹2.60/unit
3. SAEL Industries Ltd. – 100 MW @ ₹2.60/unit
* **Subject:** Petition under **Section 63 r/w Section 86(1)(b) of Electricity Act, 2003** seeking **adoption of tariff discovered under competitive bidding** (RfS No. GUVNL/250 MW/Solar (Phase XXVI), dated 18.01.2025).
* **Capacity:** 250 MW solar projects (with **greenshoe option** for additional 250 MW) – pan-India, grid-connected, without storage.

—

### Background

* Bidding process initiated by GUVNL (RfS 18.01.2025).
* Bid submission closed 17.02.2025; e-reverse auction on 03.03.2025.
* All three winners accepted **greenshoe option** → total awarded **500 MW at ₹2.60/unit**.

—

### Hearing (17.07.2025)

* GUVNL confirmed process details but admitted **supporting documents (Bid Evaluation Committee certificate, net worth verification of bidders)** had not yet been filed.
* Commission asked why full bidding details (from RfS to e-RA to petition filing) are not provided consistently.
* Commission reminded GUVNL of its earlier **Daily Order dated 17.12.2024 in Petition 2403/2024** with similar lapses.

—

### Commission’s Directions

1. GUVNL to file complete documents – bidding process record, Bid Evaluation Committee certification, net worth verification – within **1 week**.
2. Directed that **all future tariff adoption petitions** must include the full bidding process trail.
3. Next hearing scheduled for **24.07.2025 at 11:30 hrs**.

—

### Status

* **Matter adjourned.**
* Adoption of tariff for 500 MW (Welspun, Avaada, SAEL @ ₹2.60/unit) **pending** until GUVNL submits required documents.

—

For more information please see below link:

—

## **Detailed Summary – SJVN 3 MW Solar EPC + O\&M Tender (Bihar)**

### Project Overview

* **Tendering Authority:** *SJVN Limited* (Renewable Energy Division, Shimla)
* **Project Capacity:** **3 MW** grid-connected solar PV power plant
* **Location:** Bihar
* **Scope of Work:**

* Complete **EPC (Engineering, Procurement & Construction)** including design, engineering, supply, installation, testing, and commissioning.
* **Comprehensive Operation & Maintenance (O\&M) for 10 years** after commissioning, covering preventive/predictive/corrective maintenance, module cleaning, manpower, and spares.

This is part of SJVN’s ongoing push to expand its renewable energy footprint across states, supporting India’s 500 GW RE target.

—

### Timeline

* **Tender Published:** 06.08.2025
* **Bid Submission Deadline:** 28.08.2025 (14:00 hrs)
* **Technical Bid Opening:** 29.08.2025 (15:00 hrs)
* **Financial Bid Opening:** To be notified after evaluation.

This tight schedule indicates SJVN wants to finalize contractors quickly for execution.

—

### Financials

* **Estimated Project Cost:** ₹15.42 crore
* **Earnest Money Deposit (EMD):** ₹30.84 lakh
* **Tender Fee:** ₹5,000 (incl. GST)

The 10-year O\&M bundled into EPC ensures life-cycle cost optimization and accountability from the contractor.

—

### Eligibility Criteria

**Technical Experience:**

* EPC of grid-connected solar projects ≥1 MW in the past 7 years, with one of the following:

* One project ≥80% capacity (≥2.4 MW), OR
* Two projects ≥50% each (≥1.5 MW), OR
* Three projects ≥40% each (≥1.2 MW).
* Must have executed solar evacuation at **11 kV or higher**, ensuring grid readiness.

**Financial Strength:**

* Average annual turnover ≥₹4.63 crore in the last 3 years.
* Positive net worth in the last financial year.

—

### Strategic Significance

1. **Decentralized Solar Growth in Bihar:** Strengthens renewable presence in a state traditionally dependent on coal-based power imports.
2. **Lifecycle Accountability:** With **10 years O\&M**, SJVN ensures long-term performance and sustained output, reducing risk of early plant degradation.
3. **Scaling Local Solar EPC Ecosystem:** Encourages participation of medium-to-large EPC players with prior solar experience.
4. **Alignment with National Targets:** Supports India’s commitment to **50% electricity from renewables by 2030**.

—

### Expected Outcomes

* Adds **3 MW of clean capacity** to Bihar’s grid.
* Avoids \~4,000 tonnes of CO₂ annually (approximate estimate for 3 MW solar).
* Creates jobs locally during EPC and long-term O\&M.
* Demonstrates viability of bundling **long-term O\&M with EPC contracts**.

—

For more information please see below link:

—

## **Case Summary – Gujarat Urja Vikas Nigam Ltd. (GUVNL) vs. Welspun Renewable Energy Ltd. & Ors.**

**Forum:** Gujarat Electricity Regulatory Commission (GERC), Gandhinagar
**Petition No.:** 2484 of 2025
**Order Date:** 29 July 2025
**Coram:**

* Mehul M. Gandhi, Member
* S.R. Pandey, Member

—

### **1. Case Background**

* **Petitioner:** Gujarat Urja Vikas Nigam Limited (GUVNL)

* Counsel: Mr. M.K. Jani, Mr. K.N. Brahmbhatt
* **Respondents:**

1. Welspun Renewable Energy Ltd. – *no appearance*
2. Avaada Energy Pvt. Ltd. – represented by Mr. Vijay Balasubramaniam
3. SAEL Industries Ltd. – represented by Ld. Adv. Mr. Sarvaswa Chhajer
* **Nature of Petition:** Filed under **Section 63 read with Section 86(1)(b)** of the Electricity Act, 2003 seeking **adoption of tariff discovered under competitive bidding** (RfS No. GUVNL/250 MW/Solar (Phase XXVI), dated 18.01.2025).

—

### **2. Tender / Bidding Process Background**

* **Capacity:** 250 MW Grid-connected Solar PV Projects (with **greenshoe option** of additional 250 MW).
* **Process:** Tariff discovered through **competitive bidding followed by e-Reverse Auction**.
* **Project Status:** Projects may be new, under-construction, or already commissioned, located anywhere in India.
* **Net Worth Requirement (RfS 18.01.2025):** ₹0.928 crore/MW.

—

### **3. Petitioner’s Submissions**

* Submitted **Bid Evaluation Report** confirming successful bidders met net worth requirement:

* **Welspun Renewable Energy Ltd.:** ₹1,191.74 crore
* **Avaada Energy Pvt. Ltd.:** ₹7,065.71 crore
* **SAEL Industries Ltd.:** ₹2,390.17 crore
* **CUF (Capacity Utilisation Factor) quoted by bidders:**

* Welspun: 28.9%
* Avaada: 22%
* SAEL: 29%

—

### **4. Respondents’ Submissions**

* **Avaada Energy & SAEL Industries:** No objection to adoption of discovered tariff.
* **Welspun:** Absent at hearing (24.07.2025), no communication received.

—

### **5. Commission’s Observations & Directions**

* All arguments completed; matter is procedurally ready.
* All parties permitted to file **written submissions within 1 week** from order date.
* **Matter reserved for final order.**

—

### **6. Outcome**

* **Type of Order:** Procedural (post-hearing).
* **Effect:** Competitive bidding process validated, objections closed, written submissions allowed.
* Tariff adoption to be confirmed in **final order (pending)**.

—

For more information please see below link:

—

## **SJVN Limited – Tender Notice**

### Project Details

* **Work Title:** Operation & Maintenance (O\&M) of **5 MW Solar PV Plant** at **Charanka Solar Park, Gujarat**.
* **Tender No.:** SJVN/RE/01/2025
* **Location:** Charanka, Gujarat.
* **Scope:**

* Comprehensive O\&M of the **5 MW solar plant**.
* Includes preventive, predictive & corrective maintenance.
* Supply of spare parts, replacements, cleaning, manpower, security, etc.

—

### Timeline

* **Tender Publish Date:** 08.08.2025
* **Bid Submission Deadline:** 02.09.2025 (up to 14:00 hrs)
* **Technical Bid Opening:** 03.09.2025 (15:00 hrs)
* **Financial Bid Opening:** To be notified later.

—

### Financials

* **Estimated Cost:** ₹5.63 crore
* **EMD:** ₹11.26 lakh
* **Completion Period:** **3 Years** (O\&M contract duration)

—

### Eligibility Criteria

* Experience of having completed **similar O\&M work for ≥2 MW solar plants** in last 7 years.
* At least **one project of 2 MW or higher** capacity.
* Average annual turnover: **₹1.69 crore** in last 3 years.
* Net worth must be positive in last FY.

—

### Tender Authority

* **Issuer:** SJVN Limited (A Govt. of India Enterprise).
* **Address:** Renewable Energy Division, Shimla (HP).

—

For more information please see below link:

—

## **SJVN Limited – Tender Notice**

### Key Details

* **Tender Title:** *Supply, Installation, Testing & Commissioning (SITC) of 2.25 MW (AC) Solar PV Power Project at SJVN’s Corporate Office Complex, Shimla*
* **Tender No.:** PCD-SOLAR-2025-26/01
* **Estimated Cost:** ₹11.57 Crore
* **Completion Period:** 12 months from LOA
* **Bid Security (EMD):** ₹23,15,000
* **Document Fee:** ₹11,800 (inclusive of GST)

—

### Important Dates

* **Publishing Date:** 10.08.2025
* **Document Download Start:** 10.08.2025
* **Pre-Bid Meeting:** 21.08.2025 (Hybrid: Shimla Office + Online)
* **Bid Submission Deadline:** 05.09.2025 (up to 14:00 hrs)
* **Technical Bid Opening:** 05.09.2025 (15:00 hrs)
* **Financial Bid Opening:** To be notified later

—

### Scope of Work

* **Turnkey EPC Contract:**

* Supply, Installation, Testing & Commissioning of **2.25 MW (AC) Solar PV Power Plant**.
* Plant located within **SJVN’s Corporate Office Complex, Shimla**.
* Includes all associated civil, electrical, mechanical works, grid integration, protection systems.
* **O\&M:** Contractor to provide **5 years Comprehensive O\&M** after commissioning.

—

### Eligibility Criteria

* Experience of having executed at least **1 EPC solar project ≥1 MW** in the last **7 years**.
* Annual turnover ≥₹3.47 Crore (30% of tender value) in any of the last 3 years.
* Positive net worth in last FY.
* Consortium/JV allowed (max 2 members).

—

### Submission Mode

* **E-tender only** via [www.srmetenders.in](http://www.srmetenders.in)
* **Two-part bid:**

* Part I – Techno-commercial
* Part II – Financial

—

### Tender Authority

* **Issuing Authority:** SJVN Limited (Mini Ratna & Schedule ‘A’ PSU)
* **Location:** Corporate Office, Shimla, Himachal Pradesh

—

For more information please see below link:

—

## **SJVN Limited – Tender Notice**

### Key Details

* **Tender Title:** *Operation & Maintenance (O\&M) of 2.75 MW Solar PV Power Plant at SJVN Office Complex, Baddi (Himachal Pradesh)*
* **Tender No.:** PCD-OM-2025-26/02
* **Estimated Value:** ₹3.16 Crore
* **Duration:** 3 years (36 months)
* **Bid Security (EMD):** ₹6,33,000
* **Document Fee:** ₹5,900 (inclusive of GST)

—

### Timeline

* **Publishing Date:** 14.08.2025
* **Document Download Start:** 14.08.2025
* **Pre-Bid Meeting:** 25.08.2025 (online, MS Teams)
* **Bid Submission Deadline:** 09.09.2025 (up to 14:00 hrs)
* **Technical Bid Opening:** 09.09.2025 (15:00 hrs)
* **Financial Bid Opening:** To be notified later

—

### Scope of Work

* Complete **Operation & Maintenance (O\&M)** of the 2.75 MW solar plant at Baddi campus.
* Includes:

* Regular operation of plant & equipment
* Preventive & breakdown maintenance
* Module cleaning, monitoring, spares replacement
* Ensuring plant performance ratio as per contractual standards
* Contract valid for **3 years**

—

### Eligibility Criteria

* Bidders must have **experience in O\&M of solar PV plants** of **≥1 MW capacity**, completed in the last **7 years**.
* Annual financial turnover of at least **₹94.8 lakh (30% of tender value)** in any of the last 3 years.
* Positive net worth required.
* Joint ventures/consortiums allowed (max 2 partners).

—

### Submission Mode

* **E-tendering only** via [www.srmetenders.in](http://www.srmetenders.in)
* Two-part bid:

* Part I – Techno-commercial bid
* Part II – Financial bid

—

### Tender Authority

* **Issuing Authority:** SJVN Limited (A Mini Ratna & Schedule ‘A’ PSU)
* **Office:** Corporate Office, Shimla, Himachal Pradesh

—

For more information please see below link:

—

## **Case Summary – Gujarat State Electricity Corporation Ltd. (GSECL) vs. Gujarat Urja Vikas Nigam Ltd. (GUVNL)**

**Forum:** Gujarat Electricity Regulatory Commission (GERC), Gandhinagar
**Petition No.:** 2505 of 2025
**Order Date:** 08 August 2025
**Coram:**

* Mehul M. Gandhi, Member
* S.R. Pandey, Member

—

### **1. Case Background**

* **Petitioner:** Gujarat State Electricity Corporation Limited (GSECL)

* Counsel: Mr. Shubhadeep Sen, Mr. Nitin B. Kansara
* **Respondent:** Gujarat Urja Vikas Nigam Ltd. (GUVNL)

* Counsel: Mr. K.N. Brahmbhatt, Mr. Kishore Lakhani
* **Nature of Petition:** Under **Sections 62 & 86(1)(a)** of the Electricity Act, 2003 for tariff determination of **10 MW Solar PV Grid-connected Project at Anida, District Bhavnagar**, established by GSECL.

—

### **2. Petitioner’s Submissions**

* Project declared **Commercial Operation Date (COD): 07.02.2024**.
* Requested **interim tariff @ 95%** of claimed tariff as provisional arrangement, subject to final determination, to mitigate O\&M expenses and financial obligations.
* Agreed to place on record within **2 weeks**:

* EPC, civil, and O\&M contracts
* Loan agreements & equity deployment Board Resolutions
* Copy of PPA, technical and project particulars
* Agreed to issue **public notice** for stakeholder comments.

—

### **3. Respondent’s Submissions**

* Sought **additional time to file reply**.

—

### **4. Commission’s Observations & Directions**

* Petition is maintainable under Sections 62 & 86(1)(a); GSECL is a generating company and GUVNL a licensee – Commission has jurisdiction.
* Directed Petitioner to:

* Issue **public notice** in 2 Gujarati + 1 English newspapers inviting stakeholder comments within 30 days.
* Upload petition & documents on website.
* File compliance affidavit with copies of published notices.
* Commission staff to:

* Upload petition on GERC website.
* Forward received objections to Petitioner & notify objectors for hearing.
* Respondent (GUVNL) to file reply within **4 weeks** (copy to Petitioner).
* Petitioner may file rejoinder within **3 weeks** thereafter (copy to Respondent & objectors).
* On interim tariff request: Commission ruled that **parties must act as per PPA terms** for payments.
* Next hearing date to be communicated separately.

—

### **5. Outcome**

* **Type of Order:** Procedural / Interim directions
* **Effect:** Public consultation process initiated; timelines fixed for reply and rejoinder.
* Interim tariff not approved; existing PPA terms prevail.

—

For more information please see below link:

—

## **Case Summary – Gujarat State Electricity Corporation Ltd. (GSECL) vs. Gujarat Urja Vikas Nigam Ltd. (GUVNL)**

**Forum:** Gujarat Electricity Regulatory Commission (GERC), Gandhinagar
**Petition No.:** 2506 of 2025
**Order Date:** 08 August 2025
**Coram:**

* Mehul M. Gandhi, Member
* S.R. Pandey, Member

—

### **1. Case Background**

* **Petitioner:** Gujarat State Electricity Corporation Limited (GSECL)

* Counsel: Mr. Shubhadeep Sen, Mr. Nitin B. Kansara
* **Respondent:** Gujarat Urja Vikas Nigam Ltd. (GUVNL)

* Counsel: Mr. K.N. Brahmbhatt, Mr. Kishore Lakhani
* **Nature of Petition:** Under **Sections 62 & 86(1)(a)** of the Electricity Act, 2003 seeking determination of tariff for **10 MW Solar PV Grid-connected Project** at **Paravadi, Bhavnagar District**, developed by GSECL.

—

### **2. Petitioner’s Submissions**

* Project commissioned on **08.06.2024**.
* Requested **interim tariff @ 95%** of claimed tariff, pending final determination, to mitigate O\&M and financial obligations.
* Agreed to file within **2 weeks**:

* EPC, civil, and O\&M contracts
* Loan agreements & equity deployment board resolutions
* Copy of PPA, technical details, project particulars
* Agreed to issue **public notice** inviting stakeholder comments.

—

### **3. Respondent’s Submissions**

* Requested additional time to file reply in the matter.

—

### **4. Commission’s Observations & Directions**

* Petition is maintainable under Sections 62 & 86(1)(a); Commission has jurisdiction.
* Directed Petitioner to:

* Issue **public notice** in 2 Gujarati & 1 English daily newspapers inviting stakeholder objections/comments within 30 days.
* Upload petition and documents on its website.
* File compliance affidavit with published notice copies.
* Directed Commission staff to:

* Upload petition on GERC website.
* Forward objections to Petitioner and notify objectors for hearing.
* Directed Respondent to file reply within **4 weeks** (copy to Petitioner).
* Petitioner allowed to file rejoinder within **3 weeks** thereafter (copy to Respondent & objectors).
* On interim tariff request: Commission held that **payments to be made as per PPA terms**.
* Next hearing date to be communicated separately.

—

### **5. Outcome**

* **Type of Order:** Procedural / Interim directions
* **Effect:** Stakeholder consultation initiated, timelines fixed for reply/rejoinder.
* Interim tariff not approved; parties to follow PPA terms.

—

For more information please see below link:

—

## **Case Summary – Gujarat State Electricity Corporation Ltd. (GSECL) vs. Gujarat Urja Vikas Nigam Ltd. (GUVNL)**

**Forum:** Gujarat Electricity Regulatory Commission (GERC), Gandhinagar
**Petition No.:** 2507 of 2025
**Order Date:** 08 August 2025
**Coram:**

* Mehul M. Gandhi, Member
* S.R. Pandey, Member

—

### **1. Case Background**

* **Petitioner:** Gujarat State Electricity Corporation Limited (GSECL)

* Counsel: Mr. Shubhadeep Sen, Mr. Nitin B. Kansara
* **Respondent:** Gujarat Urja Vikas Nigam Ltd. (GUVNL)

* Counsel: Mr. K.N. Brahmbhatt, Mr. Kishore Lakhani
* **Nature of Petition:** Filed under **Sections 62 & 86(1)(a) of the Electricity Act, 2003** seeking determination of tariff for **35 MW Solar PV Power Project** at **Khandiya, District Surendranagar**, developed by GSECL.

—

### **2. Petitioner’s Submissions**

* Project commissioned in phases:

* 17.57 MW – 19.03.2022
* 8.14 MW – 05.07.2022
* 9.435 MW – 10.08.2022
* Requested **interim tariff @ 95%** of claimed tariff to cover O\&M and obligations pending final tariff determination.
* Agreed to file within 2 weeks:

* EPC, civil, and O\&M contracts
* Loan agreements & board resolutions for equity
* Copy of PPA, technical details, project particulars
* Agreed to issue **public notice** inviting stakeholder comments.

—

### **3. Respondent’s Submissions**

* Sought **time to file reply** in the matter.

—

### **4. Commission’s Observations & Directions**

* GSECL is a generating company; GUVNL is a licensee – matter falls under Commission’s jurisdiction.
* Directed Petitioner to:

* Issue **public notice** in 2 Gujarati + 1 English newspaper with petition details & invite stakeholder objections within 30 days.
* Upload petition and documents on its website for stakeholder access.
* File compliance affidavit with published notices.
* Directed Commission staff to:

* Upload petition on GERC website.
* Forward received stakeholder objections to Petitioner and notify objectors for hearing.
* Directed Respondent (GUVNL) to file reply within **4 weeks** (copy to Petitioner).
* Petitioner allowed to file rejoinder within **3 weeks** thereafter (copy to Respondent & objectors).
* On **interim tariff request (95%)**, Commission held parties should act as per existing **PPA terms** for energy payments.
* Next hearing date to be intimated separately.

—

### **5. Outcome**

* **Type of Order:** Procedural / Interim directions
* **Effect:** Public consultation process initiated; timelines set for reply, rejoinder, and stakeholder objections.
* Interim tariff not granted – parties to continue under PPA terms.

—

For more information please see below link:

—

## **Tender Summary – SJVN Green Energy Limited (SGEL)**

**Document Type:** Notice Inviting Tender (NIT) / Request for Selection (RfS)
**Issued by:** SJVN Green Energy Limited (a wholly owned subsidiary of SJVN Ltd.)
**Tender No.:** SGEL/BD/1500MW/India/2025/01
**Date:** 05.08.2025

—

### **1. Key Dates**

* **Tender Document Availability:** 05.08.2025 to 15.09.2025 (till 11:00 hrs IST)
* **Pre-Bid Meeting:** 19.08.2025 at 11:00 hrs (online)
* **Bid Submission Deadline:** 15.09.2025 up to 11:00 hrs
* **Technical Bid Opening:** 15.09.2025 at 15:00 hrs
* **Financial Bid Opening:** To be intimated later (only for qualified bidders)
* **Project Completion:** Timelines as per bid capacity & project location, detailed in RfS

—

### **2. Work Description**

**Name of Work:**
Selection of **Solar Power Developers (SPDs)** for development of **1,500 MW ISTS-connected Solar PV Power Projects** in India.

**Scope:**

* Design, engineering, procurement, construction, commissioning, and operation of grid-connected solar PV power projects.
* **Bid Capacity Limits:**

* Minimum: 50 MW
* Maximum: 750 MW per bidder
* Projects to be awarded through **tariff-based competitive bidding** followed by **e-Reverse Auction (e-RA)**.
* Successful bidders to sign **Power Purchase Agreement (PPA) with SGEL for 25 years**.

—

### **3. Estimated Cost & Fees**

* **Tender Fee:** ₹29,500 (inclusive of GST)
* **Earnest Money Deposit (EMD):** ₹11.80 lakh per MW (BG/online payment)
* **Performance Bank Guarantee (PBG):** ₹29.50 lakh per MW (upon award)

—

### **4. Eligibility / Prequalification Criteria**

* **Technical:**

* Experience in commissioning grid-connected solar PV/wind projects (capacity requirements specified in RfS).
* **Financial:**

* Net worth ≥ ₹1.06 crore per MW of quoted capacity.
* Minimum annual turnover and internal accruals requirements.
* **Other Conditions:**

* Compliance with “Class-I Local Supplier” norms (≥50% local content).
* Bidders from countries sharing land borders with India must be registered with Competent Authority.
* No blacklisting by any government agency.

—

### **5. Procurement & Submission**

* **Mode:** Online submission via designated e-tender portal.
* **Two-Envelope System:**

* **Part-I:** Technical Bid (eligibility, project details, compliance).
* **Part-II:** Financial Bid (tariff quoted in ₹/kWh).
* Physical submission required for original BGs/EMD and specific supporting documents.

—

### **6. Evaluation & Award**

* **Stage 1:** Techno-commercial evaluation of bids.
* **Stage 2:** Opening of financial bids of technically qualified bidders.
* **Stage 3:** e-Reverse Auction to determine lowest tariff (L1).
* Projects awarded on project-wise basis subject to bidder capacity limits.
* PPA signed with SGEL for 25 years from Scheduled COD.

—

### **7. Important Clauses**

* **Commissioning Timeline:** As per capacity/location (RfS specifies detailed schedule).
* **Liquidated Damages:** For delay in commissioning beyond scheduled COD.
* **Curtailment Compensation:** Provided in case of offtake constraints (as per PPA).
* **No tariff escalation** during the PPA term.
* **Grid Code Compliance:** All projects must meet renewable energy and ISTS grid standards.

—

### **8. Contact**

**Chief General Manager (BD)**
SJVN Green Energy Limited

—

For more information please see below link:

—

### Tender Summary

**Issuing Authority:** Rajasthan Electronics & Instruments Limited (REIL), Jaipur
**Tender No.:** REIL/RE/25-26/81 (Dated 19.08.2025)
**Title:**
Survey, Design, Supply, Erection, Testing, Commissioning and Comprehensive O\&M (25 years) of **25 MW Grid Connected Rooftop Solar PV Power Projects** on State Government/Undertaking buildings in Rajasthan.

—

### Main Details

* **Capacity:** 25 MW (Jodhpur District)
* **Estimated Tender Value:** ₹123.62 Crore
* **Bid Security (EMD):** ₹8,70,000 per MW (i.e., up to ₹21.75 Cr if bidding for full 25 MW)
* **Contract Type:** Open Tender (Domestic) + Tender-cum-e-Reverse Auction
* **Bidding System:** Single Stage, Two Envelope (Technical + Financial)
* **Bid Validity:** 90 days from opening

—

### Important Dates

* **Published Date:** 19.08.2025 (17:35 hrs)
* **Clarification Period:** 19.08.2025 – 06.09.2025 (up to 17:00 hrs)
* **Pre-Bid Meeting:** 04.09.2025, 11:00 hrs (Hybrid: REIL Office Jaipur + Zoom)
* **Bid Submission Deadline:** 16.09.2025, up to 17:00 hrs
* **Techno-Commercial Bid Opening:** 17.09.2025, 17:00 hrs
* **Financial Bid Opening:** To be notified later to eligible bidders

—

### Eligibility Highlights

* Only **Class-I Local Suppliers** eligible
* Minimum bid capacity: **5 MW**; Maximum: **25 MW**
* Must not be blacklisted, insolvent, or in conflict of interest
* Must comply with **Make in India Order 2017** & **Land Border Guidelines**

—

### Submission

* **Online only** via [eprocure.gov.in](http://www.eprocure.gov.in) (No physical offers accepted except originals of scanned documents like EMD)
* **Two Covers:**

* Cover I: Technical Bid (all eligibility + signed Integrity Pact etc.)
* Cover II: Financial Bid (Price BOQ as per format)

—

For more information please see below link:

—

## **Tender Notice – EPC Package for 50 MW Solar PV Project at Gujarat**

**Issued by:** SJVN Limited
**Tender No.:** SJVN/C\&P/IT/2025/EPC/50MW/GJ
**Date of Issue:** 05 August 2025
**Mode of Bidding:** Domestic Competitive Bidding – Open, Single Stage Two-Envelope

—

### **Objective**

SJVN invites online bids for the **design, engineering, procurement & construction (EPC) of a 50 MW grid-connected solar PV power project in Gujarat**, along with **10 years of comprehensive O\&M services**.

—

### **Key Dates**

* **Tender Publication:** 05.08.2025
* **Pre-Bid Meeting:** 13.08.2025 (11:00 hrs)
* **Last Date for Bid Submission:** 04.09.2025 (14:00 hrs)
* **Opening of Technical Bids:** 05.09.2025 (15:00 hrs)
* **Opening of Price Bids:** To be notified later (only for technically qualified bidders)

—

### **Eligibility Criteria**

1. **Technical Experience:**

* Executed at least **1 solar power project ≥40 MW**, OR
* 2 projects ≥25 MW each, OR
* 3 projects ≥20 MW each in the last 7 years.

2. **Financial Strength:**

* Average annual turnover of **₹250 Cr or more in the last 3 years**.
* Positive net worth as per latest audited financial year.

3. **Other Requirements:**

* PAN, GST, EPF, ESI compliance.
* No blacklisting by PSU/Government.

—

### **Tender Fee & Bid Security**

* **Tender Fee:** ₹29,500 (non-refundable).
* **Earnest Money Deposit (EMD):** ₹5 Crores, via Bank Guarantee or Online Payment.

—

### **Scope of Work**

* Complete **EPC package** for 50 MW Solar PV Project:

* Civil & electrical works, module mounting structures, transmission line up to interconnection point.
* Testing, commissioning, and synchronization with state grid.
* **10 Years O\&M**: Preventive & corrective maintenance, spares, manpower, performance guarantees.

—

### **Evaluation & Award**

* **Two-Envelope Bidding:** Technical + Financial.
* Only technically qualified bidders’ price bids will be opened.
* L1 bidder awarded contract.
* SJVN reserves rights to accept/reject bids without assigning reasons.

—

### **Submission Process**

* Bids must be submitted **online only** via CPP Portal ([https://eprocure.gov.in/eprocure/app](https://eprocure.gov.in/eprocure/app)).
* Manual/offline bids will not be accepted.

—

### **Contact**

**Chief General Manager (C\&P)**
SJVN Limited
Shakti Sadan, Corporate Office, Shanan, Shimla – 171006, Himachal Pradesh
[cnp@sjvn.nic.in](mailto:cnp@sjvn.nic.in) | [www.sjvn.nic.in](http://www.sjvn.nic.in)

—

For more information please see below link:

—

## **Tender Notice – Hiring of Agency for Operation & Maintenance (O\&M) of 1320 MW Thermal Power Plant**

**Issued by:** SJVN Thermal Pvt. Ltd. (Subsidiary of SJVN Ltd.)
**Tender No.:** STPL/C\&P/22-23/CS/107
**Date of Issue:** 06 August 2025
**Mode of Bidding:** Domestic Competitive Bidding – e-Tender (Open, Two-Stage)

—

### **Objective**

SJVN Thermal Pvt. Ltd. (STPL) invites online bids for **hiring an experienced O\&M agency** for providing **Operation & Maintenance services** of its **1320 MW (2×660 MW) Buxar Thermal Power Project**, located in **Buxar District, Bihar**.

—

### **Key Dates**

* **Publication on CPP Portal:** 06.08.2025
* **Start of Bid Submission:** 06.08.2025 (10:00 hrs)
* **Last Date for Clarifications:** 21.08.2025 (17:00 hrs)
* **Last Date for Online Bid Submission:** 06.09.2025 (14:00 hrs)
* **Opening of Technical Bids:** 08.09.2025 (15:00 hrs)
* **Opening of Price Bids:** To be notified later (for qualified bidders)

—

### **Eligibility Criteria**

1. **Experience:**

* Bidder should have successfully carried out **O\&M work for a coal-based thermal power plant of ≥500 MW capacity**, for at least **1 year within the last 7 years**.
* Alternatively, bidder must have **completed at least 1 O\&M contract of value ≥ ₹32 Cr**, OR 2 contracts ≥ ₹20 Cr each, OR 3 contracts ≥ ₹16 Cr each.

2. **Financial:**

* Average annual turnover of **₹40 Cr or more in the last 3 financial years**.
* Positive net worth as on last audited financial year.

3. **Legal & Compliance:**

* PAN, GST registration, EPF & ESIC compliance.
* No blacklisting/debarment by PSU/State/Central Government.

—

### **Tender Fee & Bid Security**

* **Tender Fee:** ₹5,000 (non-refundable).
* **EMD (Bid Security):** ₹50,00,000 (Fifty Lakhs) via online payment/DD/Bank Guarantee.

—

### **Scope of Work**

* Round-the-clock **operation and maintenance of the entire thermal power plant**, including:

* Boiler, turbine, generator units.
* Balance of Plant (BoP) systems.
* Electrical, mechanical & C\&I systems.
* Auxiliary and common facilities.
* Deployment of skilled manpower, supply of tools, consumables, and spares (as defined).
* Ensuring **safe, reliable & efficient plant performance** in line with regulatory/environmental standards.

—

### **Evaluation & Award**

* **Two-Stage Bidding:** Technical & Financial bids.
* Only technically responsive bids will qualify for price bid opening.
* Contract awarded to the **lowest evaluated (L1) bidder**.

—

### **Submission Process**

* Bidders must submit bids through the **CPP Portal** ([https://eprocure.gov.in/eprocure/app](https://eprocure.gov.in/eprocure/app)) using valid Class-III DSC.
* No manual/offline submission accepted.

—

### **Contact**

**SJVN Thermal Pvt. Ltd. (STPL)**
Buxar Thermal Power Project, District Buxar, Bihar
[tenderenquiry.sjvnthermal@sjvn.nic.in](mailto:tenderenquiry.sjvnthermal@sjvn.nic.in) | [www.sjvn.nic.in](http://www.sjvn.nic.in)

—

For more information please see below link:

—

## **Tender Summary – NHPC: Rooftop Solar Plants in Manipur (Phase-II, RESCO Mode)**

**Tendering Authority:** NHPC Limited (on behalf of NHPC Renewable Energy Ltd – NHPC REL, its wholly owned subsidiary)
**Tender ID:** 2025\_NHPC\_869731\_1
**Tender Ref. No.:** NH/CCW/CC-I/CO-368/PR61325/3 dated 29.05.2025
**Project Type:** Grid-Connected Rooftop Solar Plants on Government Buildings (RESCO Mode)
**Bidding Process:** Domestic Competitive Bidding – Single Stage, Two-Part (Techno-Commercial + Financial) with **e-Reverse Auction (e-RA)**

—

### **Project Scope**

* Selection of **Roof Top Developer (RTD)** for setting up solar rooftop plants at multiple government building sites across **Manipur**.
* Implementation under **RESCO Model** (developer invests, operates, and sells power).
* Part of **Phase-II rooftop solar program**.

—

### **Key Tender Details**

* **Cost of Bid Document:** ₹5,000/- (Demand Draft in favour of NHPC Ltd., payable at Faridabad)
* **Bid Security (EMD):** ₹35,63,000/- (DD/BG/POI/Insurance Surety Bond)
* **Bid Validity:** 120 days from last date of submission
* **Commissioning Timeline:** 9 months from PPA signing

—

### **Eligibility Criteria**

**A. Technical**

* Must have executed cumulative **≥400 kWp grid-connected solar PV projects**, with at least **one project ≥40 kWp**.
OR
* Experience as Solar PV Developer meeting the same capacity criteria.
OR
* EPC/developer experience in infrastructure/industry projects of **₹4 Cr+** plus at least **one 11 kV substation project**.

**B. Financial**

* **Average Annual Turnover:** ≥ ₹9.50 Cr (last 3 years)
* **Net Worth:** Positive in at least 2 of last 3 years (must be positive in immediately preceding year)
* **Working Capital:** ≥ ₹5.28 Cr

**C. Bidding Entities**

* Indian registered entities (sole bidder/JV/consortium up to 3 members).
* JV rules: lead partner ≥50% shareholding; others ≥20%.
* No blacklisting/termination due to poor performance in past 5 years.

—

### **Critical Dates**

* **Publishing & Download Start:** 23.07.2025 (18:30 hrs)
* **Bid Submission Start:** 28.07.2025 (11:00 hrs)
* **Bid Submission Close:** 21.08.2025 (17:30 hrs)
* **Offline Submission (EMD/Tender Fee):** 25.08.2025 (17:00 hrs)
* **Techno-Commercial Bid Opening:** 26.08.2025 (15:00 hrs)
* **Financial Bid Opening:** To be notified later
* **e-RA:** Date & time to be intimated separately by NHPC

—

### **Contact for Tender**

**General Manager (Civil Contracts-I)**
NHPC Office Complex, Sector-33, Faridabad – 121003, Haryana
Room No. 218, 2nd Floor, Jyoti Sadan
Tel: +91 (129) 2270596
Email: [contcivil1-co@nhpc.nic.in](mailto:contcivil1-co@nhpc.nic.in)

—

For more information please see below link:

For more information please see below link:

—

## **SJVN Green Energy Limited (SGEL)**

**Document Type:** Notice Inviting Tender (NIT)
**Issued by:** SJVN Green Energy Limited (a subsidiary of SJVN Ltd.)
**Tender No.:** SGEL/BD/1500MW/India/2025/01
**Date:** 05.08.2025

—

### **1. Key Dates**

* **Tender Document Availability:** From 05.08.2025 to 15.09.2025 (up to 11:00 hrs)
* **Pre-bid Meeting:** 19.08.2025 at 11:00 hrs (online)
* **Bid Submission Deadline:** 15.09.2025 up to 11:00 hrs
* **Technical Bid Opening:** 15.09.2025 at 15:00 hrs
* **Financial Bid Opening:** To be intimated later to technically qualified bidders
* **Completion Schedule:** As per bid document (project-specific timelines)

—

### **2. Work Description**

**Name of Work:**
Selection of Solar Power Developers (SPDs) for development of **1500 MW ISTS-connected Solar PV Power Projects** in India through competitive bidding (tariff-based), followed by e-Reverse Auction (e-RA).

**Scope:**

* Design, engineering, procurement, construction, commissioning, and operation of grid-connected solar PV power projects
* Minimum bid capacity: 50 MW
* Maximum bid capacity: 750 MW per bidder
* Long-term power purchase agreement (PPA) with SGEL for 25 years

—

### **3. Eligibility / Prequalification Criteria**

* **Technical:**

* Experience in commissioning grid-connected solar PV/wind projects (capacity requirements as per bid document)
* **Financial:**

* Net worth ≥ ₹1.06 crore per MW of quoted capacity
* Minimum annual turnover and internal resource generation criteria
* **Other:**

* Compliance with “Class-I Local Supplier” norms as per DPIIT orders
* No bar/blacklisting by any government agency
* Bidders from countries sharing land borders with India must be registered with Competent Authority

—

### **4. Tender Components**

* NIT and detailed Request for Selection (RfS) document
* Instructions to bidders & bid evaluation criteria
* Draft PPA and PSA (Power Sale Agreement)
* Format for technical & financial bids
* Bank guarantee formats (EMD & performance security)

—

### **5. Procurement & Submission**

* **Tender Fee:** ₹29,500 (incl. GST)
* **EMD:** ₹11.80 lakh per MW (bank guarantee or online payment)
* **Submission Mode:** Online via e-tender portal
* Two-envelope system:

* **Part-I:** Technical bid with all eligibility documents
* **Part-II:** Financial bid (tariff in ₹/kWh)
* Physical submission of original BGs for EMD & other mandated documents

—

### **6. Evaluation & Award**

* Techno-commercial evaluation first
* Financial bids of only qualified bidders opened
* Lowest tariff (L1) discovered through e-Reverse Auction
* Award on per-project basis within bidder capacity limits
* PPA term: 25 years from scheduled commissioning date

—

### **7. Important Clauses**

* Commissioning timelines as per bid capacity & location (details in RfS)
* Liquidated damages for delay in commissioning
* Performance Bank Guarantee: ₹29.50 lakh per MW
* Compliance with renewable energy quality and grid code norms
* Curtailment compensation in case of offtake constraints (per PPA)

—

**Issued by:**
Chief General Manager (BD), SJVN Green Energy Limited

—

For more information please see below link:

—

## **Gujarat State Electricity Corporation Limited (GSECL) vs. Gujarat Urja Vikas Nigam Limited (GUVNL)**

**Forum:** Gujarat Electricity Regulatory Commission (GERC), Gandhinagar
**Petition No.:** 2508 of 2025
**Order Date:** 08 August 2025
**Coram:**

* Mehul M. Gandhi, Member
* S.R. Pandey, Member

—

### **1. Case Background**

* **Petitioner:** Gujarat State Electricity Corporation Limited (GSECL)

* Counsel: Mr. Shubhadeep Sen & Mr. Nitin B. Kansara
* **Respondent:** Gujarat Urja Vikas Nigam Limited (GUVNL)

* Counsel: Mr. K.N. Brahmbhatt & Mr. Kishore Lakhani
* **Matter:** Petition under **Section 62 read with Section 86(1)(a)** of the Electricity Act, 2003 for **determination of tariff** for **15 MW Solar PV Grid-connected Power Project** at Vithalpar, District Morbi, established by GSECL.

—

### **2. Petitioner’s Submissions**

* Project commissioned on **27.03.2024**.
* Requested **interim tariff @ 95%** of claimed tariff as an interim arrangement until final tariff determination, to meet O\&M and other operational expenses.
* Agreed to submit within **two weeks**:

* EPC, civil, and O\&M contracts
* Loan agreements and financial arrangements
* Board resolutions for equity
* Copy of PPA
* Technical details and project particulars
* Agreed to **issue public notice** inviting stakeholder comments/suggestions.

—

### **3. Respondent’s Submissions**

* Requested time to file reply in the matter.

—

### **4. Commission’s Observations & Directions**

* **Jurisdiction:** Established under Sections 62 & 86(1)(a) of the Electricity Act, 2003 (full provisions reproduced in the order).
* **Public Notice:**

* To be issued in **two Gujarati** and **one English** newspaper.
* Petition and documents to be uploaded on Petitioner’s website.
* Stakeholders to submit objections/comments within **30 days** of notice.
* Public notice to mention Petition No., subject matter, and relief sought.
* **Document Filing:**

* Compliance affidavit with published notices to be submitted.
* Commission staff to upload petition and documents on GERC website.
* **Stakeholder Engagement:**

* Commission staff to forward stakeholder submissions to Petitioner.
* Hearing notices to be issued to objectors.
* **Reply Deadlines:**

* Respondent’s reply within **4 weeks** (copy to Petitioner).
* Petitioner’s rejoinder within **3 weeks** of receiving reply (copy to Respondent).
* **Interim Tariff Request:**

* Commission directed parties to act as per PPA terms for payment; no provisional tariff granted.

—

### **5. Outcome**

* Procedural order setting timelines for public notice, document submissions, replies, and rejoinders.
* Interim relief request deferred; payments to follow existing PPA terms.
* Next hearing date to be announced separately.

—

For more information please see below link:

—

## **Gujarat State Electricity Corporation Limited (GSECL) vs. Gujarat Urja Vikas Nigam Limited (GUVNL)**

**Forum:** Gujarat Electricity Regulatory Commission (GERC), Gandhinagar
**Petition No.:** 2511 of 2025
**Order Date:** 08 August 2025
**Coram:**

* S.R. Pandey, Member
* Mehul M. Gandhi, Member

—

### **1. Case Background**

* **Petitioner:** Gujarat State Electricity Corporation Limited (GSECL)

* Counsel: Mr. Shubhadeep Sen & Mr. Nitin B. Kansara
* **Respondent:** Gujarat Urja Vikas Nigam Limited (GUVNL)

* Counsel: Mr. K.N. Brahmbhatt & Mr. Kishore Lakhani
* **Matter:** Petition under **Section 62 read with Section 86(1)(a)** of the Electricity Act, 2003 for **determination of tariff** for **40 MW Solar PV Grid-connected Power Projects** at Haripar, District Jamnagar, established by GSECL.

—

### **2. Petitioner’s Submissions**

* The project became operational in **four phases**:

1. 10 MW – 25.04.2022
2. 10 MW – 14.06.2022
3. 10 MW – 28.06.2022
4. 10 MW – 12.07.2022
* Requested **interim tariff @ 95%** of the claimed tariff as an interim arrangement to cover O\&M and obligations, subject to adjustment after final tariff determination.
* Agreed to submit supporting documents within **two weeks**, including:

* EPC, civil, and O\&M contracts
* Loan agreements and financial arrangements
* Board resolutions on equity
* Copy of PPA and technical details
* Agreed to issue **public notice** inviting stakeholder comments/suggestions.

—

### **3. Respondent’s Submissions**

* Requested time to file a reply in the matter.

—

### **4. Commission’s Observations & Directions**

* **Jurisdiction:** Confirmed under Section 62 and Section 86(1)(a) of the Electricity Act, 2003.
* **Public Notice:** Directed Petitioner to publish in **two Gujarati newspapers** and **one English newspaper** with wide circulation, and upload the petition and documents on its website. Stakeholders to file comments within **30 days** of notice.
* **Document Submission:** Petitioner to file compliance affidavit with copies of published notices.
* **Respondent’s Reply:** Due within **4 weeks** (copy to Petitioner).
* **Petitioner’s Rejoinder:** Due within **3 weeks** after receiving Respondent’s reply (copy to Respondent).
* **Stakeholder Participation:** Commission staff to forward stakeholder comments to Petitioner and issue hearing notices to objectors.
* **Interim Tariff Request:** Directed both parties to act per terms of PPA regarding payments for supplied energy — no provisional tariff granted at this stage.

—

### **5. Outcome**

* Procedural order — sets timelines for public notice, document submissions, replies, and rejoinders.
* Interim relief request deferred; parties to follow existing PPA payment terms.
* Next hearing date to be notified separately.

—

For more information please see below link:

—

## **NCRTC Invitation for Bids**

**Issued by:** National Capital Region Transport Corporation Ltd. (NCRTC)
**Bid Reference:** DM/EL/COR-OF/282
**Date of Issue:** 11 August 2025

—

### **Objective**

NCRTC invites **open e-bids** under a **Single Stage, Two Packet System** for the **Selection of Solar Power Developer** to set up a **110 MW (AC) Grid-Connected Solar PV Power Project** in Uttar Pradesh under **captive mode**.

—

### **Bid Schedule & Key Dates**

* **Bid Security:** INR 6.60 crores (BG/Demand Draft/Banker’s Cheque/FDR) valid till **20 April 2026**.

* Physical submission of original bid security by **25 Sept 2025, 15:00 hrs**.
* **Completion Period:** 18 months from signing of PPA.
* **Bid Document Availability:** 11 Aug – 25 Sept 2025 (till 15:00 hrs) on e-procurement portal.
* **Clarification Request Deadline:** 29 Aug 2025 (17:00 hrs).
* **Pre-bid Meeting:** 26 Aug 2025 at 11:00 hrs (via Video Conference).
* **Bid Submission:**

* Start: 18 Sept 2025 (15:00 hrs)
* End: 25 Sept 2025 (15:00 hrs)
* **Technical Bid Opening:** 26 Sept 2025 (15:00 hrs).

—

### **Key Instructions**

* Manual bids are **not permitted**; only electronic submission via **[https://etenders.gov.in/eprocure/app](https://etenders.gov.in/eprocure/app)**.
* Bidders must:

* Register on the e-procurement portal.
* Have Class-III Digital Signature for the authorized signatory.
* Upload scanned copies of bid security online while submitting the original physically.
* Any bid without original bid security will be **rejected**.
* Bid validity: **180 days** from bid submission deadline.

—

### **Pre-bid Meeting Details**

* Conducted via Video Conferencing.
* Request for participation to be emailed at least 2 days before meeting to **[procurementcell@ncrtc.in](mailto:procurementcell@ncrtc.in)** with company details, attendee details, and designated email ID for VC link.
* NCRTC may allow a maximum of **two email IDs** per company.
* NCRTC may conduct a second pre-bid meeting at its discretion.

—

### **Other Conditions**

* Addenda/corrigenda will be issued only via the e-procurement portal—bidders must check regularly.
* NCRTC reserves the right to accept or reject any/all bids without assigning reasons.
* Letter of Acceptance (LoA) will be sent via post/courier/hand delivery and email.

—

**Contact for Clarifications:**
**Group General Manager (Procurement)**
National Capital Region Transport Corporation Ltd.
GatiShakti Bhawan, INA, New Delhi – 110023
Tel: +91-11-24666700
Email: [procurementcell@ncrtc.in](mailto:procurementcell@ncrtc.in)

—

For more information please see below link:

—

## **Project Overview**

* **Name of Work:**
Design, Manufacture, Supply, Installation, Testing, and Commissioning of Grid-Connected Solar Project
with **Five Years Comprehensive Maintenance Contract**
* **Location:**
Various Government and Semi-Government Buildings in **Parbhani District**, Maharashtra
* **Implementing Agency:**
Maharashtra Energy Development Agency (MEDA), Pune

—

## **Bidding Process**

* **Bidding Type:**
Two-part **e-tendering**:

* Part 1: Technical Bid
* Part 2: Financial Bid (only for technically qualified bidders)

* **Tender Reference No.:**
`REN/GRID CONN. GOVT BLDGS/HINGOLI/2025-26/1R`

—

## **Key Dates**

| Activity | Date & Time |
| ————————- | ——————————————– |
| Sale & Submission of Bids | 06.08.2025, 10:00 AM to 15.08.2025, 06:00 PM |
| Technical Bid Opening | 16.08.2025 at 11:00 AM |
| Financial Bid Opening | To be announced later |

—

## **Financial Details**

| Item | Amount |
| ————————– | ——————————————— |
| **Estimated Project Cost** | ₹1,56,59,401 (₹1.56 crore) |
| **EMD (Bid Security)** | ₹1,56,500 (Online Payment Only) |
| **Tender Document Fee** | ₹22,420 (Non-refundable, incl. 18% GST) |
| **Security Deposit** | 3% of contract value via Demand Draft to MEDA |

—

## **Execution Requirements**

* Scope includes full execution:

* Design
* Manufacture
* Supply
* Installation
* Testing
* Commissioning
* **O\&M (Operation & Maintenance)** period: **5 Years**

—

## **Venue & Communication**

* **MEDA Divisional Office (Chhatrapati Sambhajinagar):**

* City Survey No. 11149, Shop No. 305, 3rd Floor, Sai Trade Centre, Railway Station Road,
Chhatrapati Sambhajinagar, 431005
* Phone: 0240-2653595

—

## **Additional Notes**

* **e-Tender Portal:** [mahatenders.gov.in](https://mahatenders.gov.in)
* **Payment Methods:**
Only via **SBI Net Banking / RTGS / NEFT**
* **Government Resolution Dated 01/12/2016** (and subsequent amendments) applies
* **Help Desk:** NIC (National Informatics Centre) – 24×7 Support at 0120-4001002/5

—

For more information please see below link:

—

### **Project Overview**

* **Title:** Request for Selection (RfS) of Solar Rooftop Power Developers
* **Total Capacity:** 1400 kW (cumulative)
* **Project Type:** Grid-connected Rooftop Solar PV Power Projects (without battery storage)
* **Mode:** RESCO/PPA (Renewable Energy Service Company / Power Purchase Agreement)
* **Bidding Type:** Tariff-based Competitive Bidding
* **Scope:** Installation on **Union Government buildings** in the following **Special Category States/UTs**:

* **Himalayan and North-East States**: Uttarakhand, Arunachal Pradesh, Assam, Meghalaya, Tripura, Mizoram, Manipur, Nagaland, Himachal Pradesh, Jammu & Kashmir
* **Union Territory:** Andaman & Nicobar Islands

—

### **Implementing Agency**

* **SJVN Limited**

* A Joint Venture of the Government of India and Government of Himachal Pradesh
* A Navratna CPSE under the Ministry of Power
* Designated as **Scheme Implementation Partner (SIP)** by MNRE for solarizing government buildings under this scheme

—

### **Key Dates**

| Activity | Date |
| ———————————– | ———————– |
| RfS Issuance | 24.07.2025 |
| Pre-bid Meeting | 04.08.2025 at 15:00 hrs |
| Last Date for Online Bid Submission | 14.08.2025 by 13:00 hrs |
| Technical Bid Opening | 14.08.2025 at 15:00 hrs |
| Hard Copy Submission Deadline | 24.08.2025 by 18:00 hrs |
| Price Bid Opening | To be intimated later |

—

### **Financial Requirements**

* **Tender Fee:** ₹5,900 (non-refundable, incl. GST)
* **Earnest Money Deposit (EMD):** ₹1,100 per kW of quoted capacity
* **Performance Bank Guarantee (PBG):** As specified in RfS

—

### **Eligibility & Bidding Structure**

* **Bidders:** Open to Rooftop Solar Power Developers (SPDs), including companies, joint ventures, or consortiums
* **Bid Format:** Single-stage, two-envelope (Technical & Financial Bids)
* **Minimum Requirements:**

* Technical eligibility (experience in solar project development)
* Financial eligibility (net worth and turnover as per criteria in Section IV)

—

### **Bid Submission & Registration**

* Bids must be submitted through the **ISN-ETS e-tender portal**
* Mandatory registration on the portal
* Submission includes:

* Power of Attorney
* Consortium Agreement (if applicable)
* Financial documents
* Technical eligibility documentation
* Declarations & Undertakings
* Bid formats (as provided in Section VII)

—

### **Project Delivery & Execution**

* Projects are to be developed under the **RESCO model**:

* The developer invests, installs, and owns the system
* Government building rooftops are used
* Power is sold under a **long-term PPA**
* **No Central Government Financial Assistance** is provided for these projects
* Fiscal incentives such as accelerated depreciation, tax holidays, etc., may be availed by bidders at their discretion

—

### **Evaluation & Selection**

* Selection based on:

* Technical qualification
* Lowest tariff offered (L1 selection method)
* No e-reverse auction is applicable
* SJVN reserves the right to cancel or modify the RfS at any stage

—

### **Contact Information**

* **SJVN Contracts Team (RTS):**

* Email: [sjvnrts.contract@sjvn.nic.in](mailto:sjvnrts.contract@sjvn.nic.in)
* Phone contacts provided for technical and commercial queries
* **ISN-ETS Portal Support:**

* Email: [support@isn-ets.com](mailto:support@isn-ets.com)
* Phone: +91-124-4229071 / 4229072

—

For more information please see below link:

—

## **Tender Overview**

* **Authority**: SJVN Limited (A JV of Govt. of India & Govt. of Himachal Pradesh)
* **Name of Work**: Selection of Rooftop Solar Power Developers (SRPDs)
* **Total Capacity**: **3276 kW**
* **Location**: Union Government buildings in:

* Telangana
* Andhra Pradesh
* Karnataka
* Tamil Nadu
* Kerala
* **Technology**: Grid-connected Rooftop Solar PV Systems (without battery backup)
* **Model**: RESCO (build-own-operate) basis with Power Purchase Agreement (PPA)

—

## **Key Dates**

| Milestone | Date |
| ———————————- | ————————————- |
| **Tender Issuance** | 23 July 2025 |
| **Pre-Bid Meeting** | 04 August 2025 at 15:00 hrs |
| **Online Bid Submission Deadline** | 13 August 2025 at 13:00 hrs |
| **Technical Bid Opening** | 13 August 2025 at 15:00 hrs |
| **Hard Copy Submission Deadline** | 23 August 2025 at 18:00 hrs |
| **Financial Bid Opening** | Will be notified to qualified bidders |

—

## **Financial Requirements**

* **Tender Fee**: ₹5,900 (inclusive of 18% GST)
* **EMD**: ₹1,000 per kW of quoted capacity

* Acceptable forms:

* Bank Guarantee
* Demand Draft
* NEFT/RTGS
* Insurance Surety Bond
* Payment on Order Instrument (POI)
* **Performance Bank Guarantee (PBG)**: Required from successful bidders after award

—

## **Eligibility Criteria**

* **Who can Bid**:

* Individual companies
* Joint ventures (JVs)
* Consortiums
* **Bidder Types**: Rooftop Solar Power Developers (SRPDs)
* **General Conditions**:

* No financial support from the Central Government
* Must have experience in EPC, O\&M, or power sector (specific technical capacity may be specified in later sections)
* **Technical Qualification**:

* Prior experience in installing and maintaining rooftop solar systems (details to be checked in bid documents)
* **Financial Qualification**:

* Minimum turnover and net worth criteria may apply based on quoted capacity (not specified in extracted sections but generally applicable)

—

## **Scope of Work**

* **Design, Supply, Installation, Testing, Commissioning (DSITC)** of rooftop solar systems
* **Operation & Maintenance (O\&M)** for the full PPA period
* **Metering, Net Metering**, and related grid compliance
* **Bidder to identify suitable rooftops** among available government buildings
* **Electricity generated** to be sold to the building occupants under the RESCO model

—

## **Bid Submission Process**

* **Mode**: Online submission through [https://www.bharat-electronictender.com](https://www.bharat-electronictender.com)
* **System**: Single-stage, two-envelope (Technical + Financial)
* **Offline Submission**: Hard copies of some documents to be submitted to SJVN by post/by hand before 23 Aug 2025
* **e-Reverse Auction**: Not applicable
* **Bidding by Cluster**: Capacity broken into state-wise clusters – bidder may quote for one or more

—

## **PPA & Project Implementation**

* **PPA Tenure**: Typically 25 years (details to be verified in final agreement)
* **Tariff**: To be discovered through competitive bidding
* **Commissioning Timeline**: Likely defined per cluster/building (to be verified in the full scope section)

—

## **Contact for Clarifications**

* **Bhupinder Kr. Dhiman** (DGM, Contracts)

* +91 94184 57513
* [sjvnrts.contract@sjvn.nic.in](mailto:sjvnrts.contract@sjvn.nic.in)
* **SJVN Website**: [www.sjvn.nic.in](http://www.sjvn.nic.in)

—

For more information please see below link:

—

## **DETAILED SUMMARY – SJVN Rooftop Solar Tender (Southern Region)**

**RfS No.:** SJVN/RTS/2025-26/Rooftop Solar-16
**Date of Issue:** 23 July 2025
**Issued by:** **SJVN Limited** – A Joint Venture of Government of India & Government of Himachal Pradesh
**Mode:** Tariff-based Competitive Bidding under RESCO Model

—

### **PROJECT OVERVIEW**

* **Scope**: Design, supply, installation, testing, commissioning, operation and maintenance of **3276 kW** grid-connected **rooftop solar PV systems** without battery backup.

* **Region**: Southern States – **Andhra Pradesh, Telangana, Karnataka, Kerala, Tamil Nadu**.

* **Target Premises**: Union Government buildings administered by:

* Ministry of Consumer Affairs, Food & Public Distribution
* Ministry of Agriculture & Farmers Welfare
* Ministry of Statistics & Programme Implementation
* Ministry of Commerce & Industry
* Ministry of Skill Development & Entrepreneurship
* Ministry of Personnel, Public Grievances & Pensions

* **Implementation Model**: **RESCO Model** – Developer installs the system at their own cost and enters a **Power Purchase Agreement (PPA)** with building owners.

* **Financial Support**: **No Central Financial Assistance (CFA)** applicable to this project as per MNRE norms (since buildings are government-owned).

—

### **BID STRUCTURE**

* **Bidding Process**: **Single-stage**, **Two-envelope** system.

* **Envelope I – Technical Bid**
* **Envelope II – Financial Bid**
* **Mode**: Through e-tendering on [ISN-ETS Portal](https://www.bharat-electronictender.com)

—

### **FINANCIAL DETAILS**

| Item | Description |
| ———————————— | ————————————————————————————— |
| **Tender Fee** | ₹5,900 (₹5,000 + 18% GST), Non-refundable |
| **EMD** | ₹1,000 per kW of quoted capacity |
| **Performance Bank Guarantee (PBG)** | To be submitted by selected bidders, terms in PPA |
| **Payment Modes for EMD** | NEFT/RTGS, Bank Guarantee, DD, Insurance Surety Bond, Payment on Order Instrument (POI) |

—

### **CRITICAL DATES**

| Event | Date & Time |
| ———————————– | —————————————————– |
| RfS Issue Date | 23 July 2025 |
| Pre-Bid Meeting | 4 August 2025 at 15:00 hrs (Delhi Office & Online) |
| Last Date for Online Bid Submission | 13 August 2025 by 13:00 hrs |
| Technical Bid Opening | 13 August 2025 at 15:00 hrs |
| Last Date for Hard Copy Submission | 23 August 2025 by 18:00 hrs |
| Financial Bid Opening | To be notified later to technically qualified bidders |

—

### **ELIGIBILITY CRITERIA**

1. **Who can apply**:

* Indian companies, Limited Liability Partnerships (LLPs), Partnerships or Consortia/JVs.
* Experience in rooftop solar projects desirable but not mandatory.
* Must have valid registration on **ISN-ETS portal**.

2. **Not eligible for exemptions**:

* Startups, MSMEs, or any entity cannot claim exemption from Tender Fee or EMD.

3. **Document Requirements**:

* PAN, GSTIN, company registration certificates.
* Financial statements (Profit & Loss, Turnover, Net Worth).
* Undertakings on legal compliance, non-blacklisting, technical capability.

—

### **RESCO MODEL FEATURES**

* SPD bears full capital cost and maintenance of solar system.
* Electricity is sold to the government entity via PPA at a discovered tariff.
* Ownership remains with SPD during the contract term.
* PPA duration and terms will be defined in the contract issued post selection.

—

### **EMD CONDITIONS**

* EMD will be **forfeited** in following cases:

* Withdrawal or modification of bid post deadline.
* Submission of false documents.
* Failure to sign PPA or submit PBG.
* If submitted as Bank Guarantee (BG), validity must be minimum 9 months from last submission date.

—

### **OTHER KEY CONDITIONS**

* **Bid Validity**: 12 months from last date of submission.
* **Consortiums/JVs**: Allowed, with proper documentation of member responsibilities and lead bidder.
* **Tariff Discovery**: Lowest bidder (L1) for each location based on per kWh basis.
* **PPA Signing**: Only after successful empanelment and issuance of LoA.
* **No claim for CFA**: Since the sites are all Union Government buildings, CFA is not applicable.

—

### **KEY CONTACT PERSONS**

| Name | Designation | Mobile |
| ———————— | ——————————————————————- | ————– |
| Mr. Bhupinder Kr. Dhiman | DGM (Contracts) | +91 9418457513 |
| Mr. Rakesh Verma | DGM (Technical) | +91 9818659069 |
| Mr. Deependra Verma | Manager | +91 8894304429 |
| Mr. Rajendra Singh Rawat | Dy. Manager | +91 8894065950 |
| **Email for queries** | [sjvnrts.contract@sjvn.nic.in](mailto:sjvnrts.contract@sjvn.nic.in) | |

—

### **ADDITIONAL NOTES**

* SJVN may disqualify any bidder for fraudulent practices or non-compliance.
* Bidders must quote tariffs inclusive of all taxes, duties, and levies.
* PPA will be non-negotiable once awarded.
* SJVN reserves right to reject any or all bids without assigning reasons.

—

For more information please see below link: